Doddamane Constructions
Welcome to the Doddamane Constructions website. By accessing or using this website, you agree to comply with and be bound by the following Terms & Conditions. If you do not agree with these terms, please do not use this website.
1. About Doddamane Constructions
Doddamane Constructions provides residential construction services including home construction, design coordination, project execution, and related construction consulting services.
All information provided on this website is intended to give users an overview of our services, approach, and experience.
2. Use of Website
By using this website, you agree that:
- You will use the website only for lawful purposes.
- You will not attempt to misuse, hack, disrupt, or damage the website.
- You will not copy or reproduce any content from the website without permission.
- You will not use the website for fraudulent inquiries or spam submissions.
Doddamane Constructions reserves the right to restrict or terminate access to the website if misuse is detected.
3. Service Information Disclaimer
The information provided on this website, including:
- Construction cost estimates
- Timelines
- Design concepts
- Service descriptions
are indicative in nature and may vary depending on:
- Site conditions
- Material selection
- Government approvals
- Client requirements
- Market price fluctuations
Actual project costs and timelines will be confirmed only after a detailed project consultation and agreement.
4. Project Timelines
Construction timelines mentioned on the website or shared during initial discussions are approximate estimates.
Actual project timelines may vary due to factors including but not limited to:
- Weather conditions
- Material availability
- Labor availability
- Client decision delays
- Payment delays
- Government approvals
Doddamane Constructions will make reasonable efforts to complete projects within the agreed timelines.
5. Payment Terms
For construction projects undertaken by Doddamane Constructions:
- Payments are typically structured in construction stage-based milestones.
- Work progresses based on timely release of stage payments by the client.
- Delays in payments may result in project delays or temporary work stoppage.
Detailed payment terms will be outlined in the project agreement signed between the client and Doddamane Constructions.
6. Client Responsibilities
Clients engaging Doddamane Constructions agree to:
- Provide accurate property documents and approvals.
- Release payments as per agreed milestones.
- Provide timely decisions regarding design, materials, and changes.
- Cooperate with project coordination requirements.
Delays in client inputs may impact project timelines.
7. Intellectual Property
All content on this website including:
- Text
- Images
- Design elements
- Logos
- Branding
- Project photographs
are the intellectual property of Doddamane Constructions unless otherwise stated.
You may not reproduce, distribute, or use this content without prior written permission.
8. Third-Party Links
The website may contain links to third-party websites for informational purposes.
Doddamane Constructions is not responsible for:
- Content on external websites
- Privacy practices of external websites
- Services offered by third parties
Users access third-party links at their own discretion.
9. Limitation of Liability
Doddamane Constructions will not be liable for:
- Any direct or indirect damages resulting from the use of this website
- Decisions made based on information provided on the website
- Delays or disruptions due to circumstances beyond reasonable control
All construction services are governed by the formal agreement signed between the client and Doddamane Constructions.
10. Changes to Terms
Doddamane Constructions reserves the right to update or modify these Terms & Conditions at any time.
Changes will be reflected on this page with the updated date.
Users are encouraged to review this page periodically.
11. Governing Law
These Terms & Conditions are governed by the laws of India.
Any disputes arising from the use of this website or services will fall under the jurisdiction of the courts of Karnataka.
12. Contact Information
For any questions regarding these Terms & Conditions, you may contact:
Doddamane Constructions